Laserfiche WebLink
SECTION 7. DISPUTES <br />7.1 Except as this Agreement otherwise provides, all claims, counterclaims, <br />disputes and other matters in question between the CITY and CONTRACTOR out of or <br />relating to this Agreement or the breach of it will be decided by mediation if the parties <br />hereto mutually agree, or in a court of competent jurisdiction within the State of Ohio, <br />County of Cuyahoga. <br />SECTION 8. SUSPENSION OF SERVICES <br />8.1 The CITY may order the CONTRACTOR to suspend, delay, or interrupt <br />all or any part of the SERVICES for such period of time as the CITY may determine to <br />be appropriate for the convenience of the CITY. <br />8.2 If the performance of all or any part of CONTRACTOR'S SERVICES are <br />for an unreasonable period of time suspended, delayed, or interrupted by an act of the <br />CITY, or by the CITY'S failure to act within a time period specified this Agreement (or if <br />no time is specified, within a reasonable time) an appropriate extension of time for the <br />performance of the SERVICES necessary as a result of such suspension, delay, or <br />interruption, shall be permitted by the CITY and the Agreement shall be modified in <br />writing accordingly. <br />8.3 If the performance of all or any part of the CONTRACTOR'S services are <br />for an unreasonable period of time defined as sixty (60) consecutive days, suspended, <br />delayed, or interrupted by an act of the CITY, or by its failure to act within the time <br />specified this Agreement (or if no time is specified, within a reasonable time, defined as <br />ten (10) days) an appropriate extension of time shall be made for any such delay in the <br />performance of this Agreement necessarily caused by such unreasonable suspension, <br />delay, or interruption, and the Agreement modified in writing accordingly. However, the <br />CONTRACTOR shall have no claim against the CITY for an increase in the contract <br />price or a payment or allowance of any kind based on any damage, loss or additional <br />expense the CONTRACTOR may suffer as a result of any delays in prosecuting or <br />completing the work under the contract, whether such delays are caused by the <br />circumstances set forth in the preceding paragraph or by any other circumstances. It is <br />5 <br />