2005-102 Resolution - Laserfiche WebLink

Home Browse Search

SECTION 6. CHANGES 6.1 The CITY may, at any time, by written order, make changes within the general scope of this Agreement in the SERVICES to be performed. 6.2 If such changes cause an increase or decrease in the CONTRACTOR'S cost of, or time required for, performance of services required under this Agreement, an equitable adjustment shall be made, and this Agreement shall be modified in writing accordingly, subject to any requirements of the laws of the City of North Olmsted, Ohio. CONTRACTOR shall not submit change orders, and shall not be entitled to additional compensation, for additional work resulting from conflicts, errors, or discrepancies, if such was discovered, or reasonably discoverable, by CONTRACTOR prior to the time it entered into this Agreement. 6.3 The CONTRACTOR shall have no claim against the CITY for an increase in the contract price or a payment or allowance of any kind based on any damage, loss or additional expense the CONTRACTOR may suffer as a result of any delays in prosecuting or completing the work under the contract., whether such delays are caused by the circumstances set forth in the preceding paragraph or by any other circumstances. It is understood that the CONTRACTOR assumes all risks of delays in prosecuting or completing the work under the contract. SECTION 7. DISPUTES 7.1 Except as this Agreement otherwise provides, all claims, counterclaims, disputes and other matters in question between the CITY and CONTRACTOR out of or relating to this Agreement or the breach of it will be decided by mediation if the parties hereto mutually agree, or in a court of competent jurisdiction within the State of Ohio, County of Cuyahoga. SECTION 8. SUSPENSION OF SERVICES 8.1 The CITY may order the CONTRACTOR to suspend, delay, or interrupt all or any part of the SERVICES for such period of time as the CITY may determine to be appropriate for the convenience of the CITY.