Laserfiche WebLink
5.2 All invoices shall be in the format requested by the CITY as referenced in Exhibit <br />II, Method of Payment. <br />5.3 The CONTRACTOR covenants and agrees to pay all persons and corporations, <br />including its employees, subcontractors, ma.terialmen, agents, and all other working in active <br />concert with it, who furnish materiais or render services in connection wi#n the performance of <br />this Agreement. <br />SECTION 6. CHANGES <br />6.1 The CITY ma.y, at any time, by written order, make changes within the general <br />scope of this Agreement in the services or work to be performed. <br />6.2 If such changes cause an increase or decrease in the CONTRACTOR's cost of, or <br />time required for, performance of required services under this Agreement, an equitable adjustment <br />shall be made, and this Agreement shall be modified in writing accordingly, subject to any <br />requirements of the laws of the Ciiy of North Olmsted, Ohio. <br />6.3 CONTRACTOR sha11 not submit change orders, and shall not be entitled to <br />additional compensation, for additional work resulting from conflicts, errors, or discrepancies, if <br />such was discovered, or reasonably discoverable, by CONTR.ACTOR prior to the time it entered <br />into this Agreement. <br />SECTION 7. DISPUTES <br />7.1 Except as this agreement otherwise provides, all claims, counterclaims, disputes <br />and other controversies between the CITY and CONTRACTOR arising out af, or relating in any <br />maiuier, to this Agreement shall be decided by arbitration in Cuyahoga County, State of Ohio, if <br />the parties hereto mutually agree, or otherwise only in a court of competent jurisdiction within <br />Cuyahoga County, State of Ohio. <br />SECTION 8. SUSPENSION OF WORK <br />8.1 The CITY may order the CONTRACTOR to suspend, delay, or interrupt all or <br />any part of the work for such period of time as the CITY may determine to be appropria.te for the <br />convenience of the CITY. <br />4