2006-117 Ordinance - Laserfiche WebLink

Home Browse Search

• ? .?*, SECTION 7. DISPUTES 7.1 Except as this agreement otherwise provides, all claims, counterclaims, disputes and other matters in question between the CITY and the CONTRACTOR out of or relating to this Agreement or the breach of it will be decided by mediation if the parties hereto mutually agree, or in a court of competent jurisdiction within the State of Ohio, County of Cuyahoga. SECTION 8. SUSPENSION OF SERVICES 8.1 The CITY may order the CONTRACTOR to suspend, delay, or interrupt all or any part of the SERVICES for such period of time as the CITY may determine to be appropriate for the convenience of the CITY. 8.2 If the performance of all or any part of CONTRACTOR's SERVICES are for an unreasonable period of time suspended, delayed, or interrupted by an act of the CITY, or by the CITY's failure to act within a time period specified this Agreement (or if no time is specified, within a reasonable time) an appropriate extension of time for the performance of the SERVICES necessary as a result of such suspension, delay, or interruption, shall be permitted by the CITY and the Agreement shall be modified in writing accordingly. SECTION 9. TERMINATION OF AGREEMENT 9.1 It is expressly understood and agreed that either the CITY or CONTRACTOR may terminate this Agreement at any time by giving 30 days advance written notice to the other party either personally to the representative of that party who signed this Agreement, or by registered mail, return receipt requested, addressed to the principal office of that party. 9.2 In the event that this Agreement is terminated by either the CITY or the CONTRACTOR, the CONTRACTOR shall only be entitled to be compensated for SERVICES performed to the date of termination. Such compensation shall be based on the provisions set forth in Exhibit III, if possible. For any services rendered to which these provisions do not apply, payment shall be based upon a per diem rate for the actual time 5