2010-005 Ordinance - Laserfiche WebLink

Home Browse Search

6.2 If such changes cause an increase or decrease in the CONTRACTOR'S cost of, or time required for, performance of services required under this Agreement, an equitable adjustment shall be made, and this Agreement shall be modified in writing accordingly, subject to any requirements of the laws of the City of North Olmsted, Ohio. 6.3 CONTRACTOR shall not submit change orders, and shall not be entitled to additional compensation, for additional work resulting from conflicts, errors, or discrepancies, if such was discovered, or reasonably discoverable, by CONTRACTOR prior to the time it entered into this Agreement. SECTION 7. DISPUTES 7.1 Except as this Agreement otherwise provides, all claims, counterclaims, disputes and other controversies between the CITY and CONTRACTOR arising out of, or relating in any manner, to this Agreement shall be decided by arbitration in Cuyahoga County, Ohio, if the parties hereto mutually agree, or otherwise only in a court of competent jurisdiction within Cuyahoga County, Ohio. SECTION 8. SUSPENSION OF SERVICES 8.1 The CONTRACTOR shall comply with and abide by North Olmsted Code Section 139.07 with respect to criminal background checks. Further, the CONTRACTOR further agrees, as a condition precedent of this Agreement, to consent to and submit to the Director of Public Safety, a criminal convictions background check on all employees of said CONTRACTOR, so employed for the purpose of or expected to perform the contractual obligations set forth herein. The City reserves the right to cancel and render this Agreement void, ab initio, if in the judgment and the sole discretion of the Director of Public Safety, the inspection of criminal records is either not satisfied or the CONTRACTOR'S history is deemed unacceptable. CONTRACTOR hereby acknowledges that the failure of this condition precedent for any reasons cited hereinabove, shall render the Agreement void, without recourse or claim by the CONTRACTOR. 8.2 The CITY may order the CONTRACTOR to suspend, delay, or interrupt all or any part of the SERVICES for such period of time as the CITY may determine to be appropriate for the convenience of the CITY. 4