2001-056 Ordinance - Laserfiche WebLink

Home Browse Search

be in accordance with the Construction Industry Arbitration Rules of the American Arbitration Association currently in eFfect. The demand for arbitration shall be filed in writing with the other party to this Agreement and with the American Arbitration Association. 7.23 A demand for arbitration shall be made within a reasonable time after the claim, dispute or other matter in question has arisen. In no event shall the demand for arbitration be made after the date when institution of legal or equitable proceedings based on such claim, dispute or other matter in question would be barred by the applicable statute of limitations. 7.2.4 No arbitration arising out of or relating to this Agreement shall include, by consolidation or joinder or in any other manner, an additional person or entity not a party to this Agreement, except by written consent containing a specific reference to this Agreernent and signed by the Owner, Architect, and any oiher person or entity sought to be joined. Consent to arbitration involving an additional person or entity shall not constitute consent to arbitration of any claim, dispute or other matter in question not described in the written consent or with a person or entity not named or described therein. The foregoing agreement to arbitrate and other agreements to arbitrate with an additional person or entity duly consented to by parties to this Agreement shall be specifically enforceable in accordance with applicable law in any court having jurisdiction thereof. 7.2.5 1'he award rendered by the arbitrator or arbitrators shall be final, and judgment may be entered upon it in accordance with applicable law in any court having jurisdiction thereof. 7.3 CLAIMS FOR CONSEQUENTIAL DAMAGES The Architect and Owner waive consequential damages for claims, disputes or other matters in question arising out of or relating to this Agreement. This ?nutual waiver is applicable, without limitation, to all consequencial damages due to either party's termination in accordance with Article 8. ARTICLE 8 TERMINATION OR SUSPENSION 8.1 If the Owner Fails to make payments to the Architect in accordance with this Agreement, such failure shail be considered substantial nonperformance and cause For termination or, at the Architect's opUon, cause for suspension of performance of services under this Agreement. If the Architect elects to suspend services, prior to suspension of services, the Architect shall give seven days' written notice to the Owner. In the event oF a suspension of services, the Architect shall have no liability to the Owner for delay or damage caused the Owner because oF such suspension of services. Before resuming services, ihe Architect shall be paid all sums due prior to suspension and any expenses incurred in the interruption and resumption of the Architect's services. The Architect's fees for the remaining services and the time schedules shall be equitably adjusted. 8.2 If the Project is suspended by the Owner for more than 30 consecutive days, the Architect shall be compensated for services performed prior to notice of such suspension. When the Project is resumed, the Architect shall be compensated for expenses incurred in the interruption and ll?? resumption of the Architect's services. The Archited's fees for the remaining services and the time o 0 schedules shall be equitably adjusted. o•. ., o a c?o•o 8.3 If the Project is suspended or the Architect's services are suspended for more than 90 0 19 97 A 1 A 0 consecutive days, the Architect may terminate this Agreement by giving not less than seven days' AIA DOCUMENi Bi51-1997 written notice. ABBREVIATED OWNER- ARCHITECT AGREEMEN7 8.4 This Agreement may be terminated by either party upon not less than seven days' wriiten The American Insiitute notice should the other party fail substantially to perform in accordance with the terms of this of Archirects Agreement through no fault oF the party initiating the termination. ?735 New York a,venue, N.W. WashingTon, D.C. 20006-5292 WARNING: Unlicensed ohotocoovina violarr.c ILS rnnvriahr I-- ,.,a ,.,u1 -ti;e...t,., ,,:,,i..,,, -- i,,,._i