2017-011 Resolution - Laserfiche WebLink

Home Browse Search

Substantial Completion is the stage in the progress of the Work when the Work or designated portion thereof is sufficiently complete in accordance with the Contract Documents so the CITY can occupy or utilize the Work, or the designated portion thereof, for its intended use subject to punch list items which do not materially interfere with the CITY's occupancy or intended utilization of the PROJECT. 6.5 The CONTRACTOR shall have no claim against the CITY for an increase in the contract price or a payment or allowance of any kind based on any damage, loss or additional expense the CONTRACTOR may suffer as a result of any delays in prosecuting or completing the work under the contract, whether such delays are caused by the circumstances set forth in the preceding paragraph or by any other circumstances. It is understood that the CONTRACTOR assumes all risks of delays in prosecuting or completing the work under the contract. SECTION 7. DISPUTES 7.1 Except as this agreement otherwise provides, all claims, counterclaims, disputes and other matters in question between the CITY and the CONTRACTOR out of or relating to this Agreement or the breach of it will be decided by mediation if the parties hereto mutually agree, or in a court of competent jurisdiction within the State of Ohio, County of Cuyahoga. SECTION 8. SUSPENSION OF SERVICES 8.1 The CITY may order the CONTRACTOR to suspend, delay, or interrupt all or any part of the SERVICES for such period of time as the CITY may determine to be appropriate for the convenience of the CITY. 8.2 If the performance of all or any part of CONTRACTOR's SERVICES are for an unreasonable period of time suspended, delayed, or interrupted by an act of the CITY, or by the CITY's failure to act within a time period specified this Agreement (or if no time is specified, within a reasonable time) an appropriate extension of time for the performance of the SERVICES necessary as a result of such suspension, delay, or interruption, shall be permitted by the CITY and the Agreement shall be modified in writing accordingly.