Laserfiche WebLink
SECTION 7. DISPUTES <br />7.1 Except as this agreement otherwise provides, all claims, counterclaims, disputes <br />and other matters in question between the CITY and the ENGINEER out of or relating to this <br />Agreement or the breach of it will be decided by mediation if the parties hereto mutually agree, <br />or in a court of competent jurisdiction within the State of Ohio, County of Cuyahoga. <br />SECTION 8. SUSPENSION OF SERVICES <br />8.1 The CITY may order the ENGINEER to suspend, delay, or interrupt all or any part <br />of the SERVICES for such period of time as the CITY may determine to be appropriate for the <br />convenience of the CITY. <br />8.2 If the performance of all or any part of ENGINEER'S SERVICES are for an <br />unreasonable period of time suspended, delayed, or interrupted by an act of the CITY, or by the <br />CITY's failure to act within a time period specified this Agreement (or if no time is specified, <br />within a reasonable time) an appropriate extension of time for the performance of the SERVICES <br />necessary as a result of such suspension, delay, or interruption, shall be permitted by the CITY and <br />the Agreement shall be modified in writing accordingly. <br />SECTION 9. TERMINATION OF AGREEMENT <br />9.1 It is expressly understood and agreed that either the CITY or ENGINEER may <br />terminate this Agreement at any time by giving 30 days advance written notice to the other party <br />either personally to the representative of that party who signed this Agreement, or by registered <br />mail, return receipt requested, addressed to the principal office of that party. <br />9.2 In the event that this Agreement is terminated by either the CITY or the <br />ENGINEER, the ENGINEER shall only be entitled to be compensated for SERVICES performed <br />to the date of termination. Such compensation shall be based on the provisions set forth in Exhibit <br />I, if possible. For any services rendered to which these provisions do not apply, payment shall be <br />based upon a per diem rate for the actual time spent rendering the services, computed by using the <br />average rate for such services rendered by other comparable firms in Cuyahoga County, Ohio. <br />SECTION 10. INSURANCE <br />4 <br />