8739-14 Authorize asbestos removal and abatement at McKinley

Home Browse Search

alternatives to Brownfield Cleanup Analysis, Community Relations Plan, and Specifications or Remedial Action Plan, as applicable. (f) Environmental Assessments. A copy of the certified asbestos survey, Phase I Environmental Assessment and Phase 2 Environmental Assessment, as applicable. (g) Additional Documents. Such other papers and documents regarding Subgrantee, the Subgrantee's Work, the Subgrantee's contractor(s), Project Engineer or the Project as Grantor may require. 33 Conditions Precedent to All Disbursements of Subgrant Proceeds. Grantor shall not be obligated to make Disbursements (as defined in Schedule 1) unless: (a) Work Contracts. The final executed Work Contracts; (b) All conditions precedent to that Disbursement have been satisfied, including without limitation, performance of all of the then pending obligations of Subgrantee under this Agreement, and the satisfaction of any conditions and requirements of this Agreement required to be performed by any other party ; (c) Grantor shall be satisfied as to the continuing accuracy of the Budget and that Subgrantee's Work is being completed in accordance with the Specifications, the Work Schedule, and the Work Contracts. (d) No Default exists under this Agreement and no event, circumstance or condition exists which, with the passage of time or the giving of notice, would constitute a Default under this Agreement. (e) No litigation, claims or proceedings are pending or threatened against Subgrantee, or the Property, which litigation, claims or proceedings, in the sole and exclusive judgment of Grantor, would materially affect Subgrantee's ability to perform any of its respective obligations under any of this Agreement. (f) No event, circumstance or condition exists or has occurred which could, in Grantor's sole judgment, delay or prevent the completion of Subgrantee's Work by the Completion Date; (g) All representations and warranties made by Subgrantee to Grantor herein and otherwise in connection with this Grant continue to be accurate; all statements and representations made in the Grant Application continue to be accurate; (h) Grantor shall have received evidence satisfactory to it that all Grant Proceeds disbursed to date have been applied to payment of Eligible Costs;