2007-015 Ordinance - Laserfiche WebLink

Home Browse Search

6.2 If such changes cause an increase or decrease in the CONTRACTOR's cost of, or time required for, performance of services required under this Agreement, an equitable adjustrnent shall be made, and this Agreement shall be modified in writing accordingly, subject to any requirements of the laws of the City of North Olmsted, Ohio. 6.3 CONTRACTOR shall not submit claims, and shall not be entitled to additional compensation, for additional work resulting from conflicts, errors, or discrepancies, if such was discovered, or reasonably discoverable, by CONTRACTOR prior to the time it entered into this Agreement. 6.4 After Substantial Completion, if CONTRACTOR shall neglect, refuse or fail to complete the remaining Work within the Contract Time, CONTRACTOR shall pay CITY the actual costs reasonably incurred by CIT'Y for engineering and inspection forces employed on the Work for each day that expires after the time specified in Appendix C for the Work to be completed and ready for final payment (adjusted for any extensions thereof made by OWNER) until the Work is completed and ready for final payment. 6.5 The CONTRACTOR shall have no claim against the CITY for an increase in the contract price or a payment or allowance of any kind based on any damage, loss or additional expense the CONTR.ACTOR may suffer as a result of any delays in prosecuting or completing the work under the contract, whether such delays are caused by the circumstances set forth in the preceding paragraph or by any other circumstances. It is understood that the CONTRACTOR assumes all risks of delays in prosecuting or completing the work under the contract. SECTION 7. DISPUTES 7.1 Except as this agreement otherwise provides, all claims, counterclaims, disputes and other matters in question between the CITY and the CONTRACTOR out of or relating to this Agreement or the breach of it will be decided by mediation if the parties hereto mutually agree, or in a court of competent jurisdiction within the State of Ohio, County of Cuyahoga. SECTION 8. SUSPENSION OF SERVICES 4