Laserfiche WebLink
F , ,.?.....__ . . ..... _ <br />shall be made, and this Agreement shall be modified in writing accordingly, subject to any <br />requirements of the laws of the City of North Olmsted, Ohio. <br />6.3 CONTRACTOR shall not submit claims, and shall not be entitled to additional <br />compensation, for additional work resulting from conflicts, errors, or discrepancies, if such was <br />discovered, or reasonably discoverable, by CONTRACTOR prior to the time it entered into this <br />Agreement. <br />6.4 After Substantial Completion, if CONTRACTOR shall neglect, refuse or fail to <br />complete the remaining Work within the Contract Time, CONTRACTOR sha11 pay CITY the <br />actual costs reasonably incurred by CITY for engineering and inspection forces employed on the <br />Work for each day that expires after the time specified in Exhibit III for the Work to be <br />completed and ready for final payment (adjusted for any extensions thereof made by OWNER) <br />until the Work is completed and ready for final payment. <br />6.5 The CONTRACTOR shall have no claim against the CITI' for an increase in the <br />contract price or a payment or allowance of any kind based on any damage, loss or additional <br />expense the CONTRACTOR may suffer as a result of any delays in prosecuting or completing <br />the work under the contract, whether such delays are caused by the circumstances set forth in the <br />preceding paragraph or by any other circumstances. It is understood that the CONTRACTOR <br />assumes all risks of delays in prosecuting or completing the work under the contract. <br />SECTION 7. DISPUTES <br />7.1 Except as this agreement otherwise provides, all claims, counterclaims, disputes <br />and other matters in question between the CITY and the CONTRACTOR out of or relating to <br />this Agreement or the breach of it will be decided by mediation if the parties hereto mutually <br />agree, or in a court of competent jurisdiction within the State of Ohio, County of Cuyahoga. <br />SECTION 8. SUSPENSION OF SERVICES <br />8.1 The CITY may order the CONTRACTOR to suspend, delay, or inteirupt all or any <br />part of the SERVICES for such period of time as the CITY may determine to be appropriate for the <br />convenience of the CIT'I'. <br />8.2 If the performance of a11 or any part of CONTRACTOR's SERVICES are for an <br />unreasonable period of time suspended, delayed, or intemzpted by an act of the CIT'Y, or by the <br />CITY's failure to act within a time period specified this Agreement (or if no time is specified, <br />4