2003-015 Resolution - Laserfiche WebLink

Home Browse Search

unless the price is determined by the Board to be inequitable. If the price is determined to be inequitable, the Boazd shall approve the order and provide for an equitable price not to exceed Five Thousand Dollars ($5,000.00), taking into account the nature and extent of the necessity involved and the work performed, and amounts and rates paid for the same or similaz work elsewhere in Cuyahoga County, Ohio. SECTION 11. DISPUTES 11.1 The parties agree that all claims, counterclaims, disputes and other matters involving the CITY and the CONTRACTOR arising out of or relating to this Agreement, or the breach of it, will be first submitted to mediation if they mutually agree, and, following mediation, or if they do not agree to mediation, then to a court of competent jurisdiction within County of Cuyahoga, Ohio. SECTION 12 SUSPENSION OF WORK 12.1 The CITY ma.y order the CONTRACTOR to suspend, delaq, or interrupt all or any part of the work for such period of time as the CITY may determine to be appropriate for the convenience of the CITY. 12.2 If the performance of a11 or any part of the CONTRACTOR'S services are for an unreasonable period af time defined as sixty (60) consecutive days, suspended, deiayed, or interrupted by an act of the CITY, or by its failure to act within the t.ime specified this Agreement (or if no time is specified, within a reasonable time, defined as ten (10) days) an appropriate extensian of time shall be made for any such delay in the performance of this Agreement necessarily caused by such unreasonable suspension, delay, or interruption, and the Agreement modified in writing accordingly. SECTION 13 TERNIINATION OF AGREEMENT 13.1 CITY shall have the right, for its convenience, to terminate the work in whoie or in part at any time by written notice to CONTR.ACTOR. Every such notice shall state the eartent and effective date of such termination, On such effective date, Contrac,tor s